Terms of Service

Last Updated: 9 April 2026

These Terms of Service ("Terms") govern your use of the website aussierenopt.site and the services provided by Aussie Reno Pty Ltd (ABN 91 695 757 003, ACN 695 757 003), an Australian Private Company registered in Western Australia ("we," "us," or "our").

1. Acceptance of Terms

By accessing our website or engaging our renovation services, you agree to be bound by these Terms. If you do not agree to these Terms, you must not use our website or services.

2. Our Services

Aussie Reno Pty Ltd provides home renovation and building services in Western Australia, including but not limited to:

• Full home renovations, extensions, and second-storey additions
• Kitchen and bathroom remodelling
• Outdoor living areas and landscaping
• Commercial fit-outs and refurbishments

All renovation services are subject to a separate written contract that outlines the specific scope of work, timeline, pricing, and payment terms.

3. Quotes and Pricing

Quotes provided by Aussie Reno Pty Ltd are estimates based on the information available at the time of assessment. Quotes are valid for 30 days unless otherwise stated. Final pricing may vary based on:

• Changes to the project scope requested by the client
• Unforeseen structural or site conditions discovered during works
• Changes in material costs or availability
• Additional regulatory or compliance requirements

Any variations to the agreed scope of work will be communicated in writing and require client approval before proceeding.

4. Payment Terms

Payment terms are outlined in individual project contracts. Generally:

• A deposit is required before commencement of works
• Progress payments may be invoiced at agreed project milestones
• Final payment is due upon practical completion and client sign-off
• Late payments may incur interest at the rate specified in the contract

5. Client Responsibilities

As a client, you agree to:

• Provide accurate and complete information about your property and project requirements
• Ensure safe and reasonable access to the work site
• Obtain any necessary permits or approvals from local authorities (unless agreed otherwise in writing)
• Make timely decisions on material selections and design approvals to avoid project delays
• Make payments in accordance with the agreed schedule

6. Warranties and Guarantees

All renovation work carried out by Aussie Reno Pty Ltd is subject to the statutory warranties and guarantees provided under Australian Consumer Law. We stand behind the quality of our workmanship and materials used in all projects.

7. Limitation of Liability

To the maximum extent permitted by law, Aussie Reno Pty Ltd's liability for any claim arising from our services shall be limited to the value of the contracted works. We are not liable for:

• Indirect, consequential, or incidental losses or damages
• Delays caused by weather, material shortages, or circumstances beyond our reasonable control
• Pre-existing defects in the property not identified during initial assessment
• Damage resulting from client modifications to completed work

8. Intellectual Property

All content on the website aussierenopt.site, including text, graphics, logos, images, and design elements, is the property of Aussie Reno Pty Ltd and is protected by Australian intellectual property laws. You may not reproduce, distribute, or use any content without our prior written consent.

9. Website Use

You agree to use our website only for lawful purposes and in accordance with these Terms. You must not:

• Use the website in any way that violates applicable laws or regulations
• Attempt to gain unauthorised access to any part of the website
• Introduce viruses, malware, or other harmful material
• Use automated tools to scrape or collect data from the website

10. Cancellation and Termination

Either party may terminate a renovation contract in accordance with the cancellation provisions outlined in the specific project agreement. Cancellation may be subject to:

• Payment for work already completed and materials already ordered
• Reasonable administrative and restocking fees
• Any other costs incurred as a result of the cancellation

11. Dispute Resolution

In the event of a dispute, we encourage open communication to reach an amicable resolution. If a dispute cannot be resolved informally, both parties agree to attempt mediation before pursuing legal action. Any legal proceedings shall be conducted in the courts of Western Australia.

12. Force Majeure

Aussie Reno Pty Ltd shall not be liable for any failure or delay in performing our obligations due to circumstances beyond our reasonable control, including but not limited to natural disasters, pandemics, government restrictions, labour disputes, or supply chain disruptions.

13. Changes to These Terms

We reserve the right to update these Terms at any time. Changes will be posted on this page with an updated revision date. Your continued use of our website or services after changes are posted constitutes acceptance of the revised Terms.

14. Governing Law

These Terms are governed by and construed in accordance with the laws of Western Australia and the Commonwealth of Australia. You agree to submit to the exclusive jurisdiction of the courts of Western Australia for the resolution of any disputes.

15. Severability

If any provision of these Terms is found to be invalid or unenforceable, the remaining provisions shall continue in full force and effect.

16. Contact Us

If you have any questions about these Terms of Service, please contact us:

• Email: ceo@aussierenopt.site
• Website: aussierenopt.site
• ABN: 91 695 757 003
• ACN: 695 757 003